Navy construction contract regulations vs. the Board of Contract Appeals.
Loading...
Authors
McMurray, Thomas David
Subjects
Navy construction contracts
Advisors
Evered, Roger D.
Date of Issue
1987-12
Date
December 1987
Publisher
Language
en_US
Abstract
This thesis addresses construction contracting in the
United States Navy. It compares the Government construction
contract regulations with decisions by the Boards of
Contract Appeals.
Nine topics are researched including submittal reviews,
profit, change orders and changes, notices to proceed,
acceleration, beneficial occupancy, weather delays, and
extended overhead.
The Boards' decisions are used to understand the topics
and to identify weaknesses in the regulations.
Recommendations are made to improve the Naval Facilities
Engineering Command Contracting Manual (P-63).
Type
Thesis
Description
Series/Report No
Department
Administrative Sciences
Organization
Naval Postgraduate School (U.S.)
Identifiers
NPS Report Number
Sponsors
Funding
Format
102 p.
Citation
Distribution Statement
Approved for public release; distribution is unlimited.
Rights
This publication is a work of the U.S. Government as defined in Title 17, United States Code, Section 101. Copyright protection is not available for this work in the United States.